--- title: Playground Upgrades for Child Development Center at TYAD | Closed - MatchAwards description: Playground Upgrades for Child Development Center at TYAD. United States Department of the Army. Solicitation W51AA1-26-Q-A068. NAICS 236220 - Commercial and Institutional Building Construction. Total small business set-aside. Deadline 2026-07-02. Project Description: This requirement is for the... canonical: https://matchawards.com/dept_of_the_army/posts/116734164967067632 og:image: https://matchawards.com/home_logo.png og:image:width: 130 og:image:height: 130 twitter:card: MatchAwards.com twitter:image: https://matchawards.com/home_logo.png og:site_name: MatchAwards og:type: article og:title: Playground Upgrades for Child Development Center at TYAD | Closed og:url: https://matchawards.com/dept_of_the_army/posts/116734164967067632 og:description: Playground Upgrades for Child Development Center at TYAD. United States Department of the Army. Solicitation W51AA1-26-Q-A068. NAICS 236220 - Commercial and Institutional Building Construction. Total small business set-aside. Deadline 2026-07-02. Project Description: This requirement is for the... og:image: https://matchawards.com/system/accounts/avatars/000/000/092/original/04da5de8c6ff714b.png?1638996022 og:image:width: 120 og:image:height: 120 twitter:card: summary --- # Playground Upgrades for Child Development Center at TYAD Agency [United States Department of the Army](/dept%5Fof%5Fthe%5Farmy) Office TOBYHANNA, USA Notice type Solicitation Solicitation number W51AA1-26-Q-A068 NAICS [236220 - Commercial and Institutional Building Construction](/groups/212) PSC Y1PA - CONSTRUCTION OF RECREATION FACILITIES (NON-BUILDING) Category [Construction Related Services (4.2)](/categories/facilities-and-construction/construction-related-services) Set-aside [Total Small Business Set-Aside (FAR 19.5)](/contracts/small-business) Posted 2026-06-11 Deadline 2026-07-02 Place of performance Tobyhanna, Pennsylvania 18466, UNITED STATES ## Description **Project Description:** This requirement is for the construction services required to complete playground upgrades for the CDC at Tobyhanna Army Depot (TYAD). Specific work includes supply and installation of a new climbing structure for ages 0-5 (including site preparation, layout verification, equipment assembly, and secure anchoring of the structure) and the expanding of existing swing set fall zones for ages 6-10\. The construction services necessary to complete this include providing all licenses, permits, labor, materials, equipment, and supervision. **Magnitude of Construction Project:** Pursuant to FAR 36.204, the estimated magnitude of construction is: Between $75,000.00 to $150,000.00. **DBA Wage Determination:** General Decision Number PA20260018, Modification #3, Dated 1/30/2026, is currently applicable and provided as Exhibit 5. **Alternative Payment Protection:** IAW FAR 28.102-1, Offerors are to note that the awardee shall submit to the Government, within ten (10) days of award, one (1) of the following payment protections: 1. A Payment Bond; or 2. An Irrevocable Letter of Credit **Site Visit Information:** One scheduled (1) site visit will be held on Wednesday, 17 June, at 1:00 PM EST. Attendees are encouraged to arrive 15 minutes early to ensure timely processing. Visitors may be required to present a valid Government issued photo I.D.(**REAL ID is required)** to gain access to the base (vehicle registration and insurance may also be required). Information provided at each site visit, as well as answers to any general questions, shall not affect the terms and conditions of the RFP and/or specifications. Terms remain unchanged unless the RFP is amended in writing. RSVP is requested NLT Wednesday, 17 June, at 10:00 AM EST. RSVP via e-mail only to the Contracting Officer at mark.buonomo2.civ@army.mil. **Questions and Answers:** All questions must be submitted in writing to the Contracting Officer, Mark Buonomo, via e-mail only, at mark.buonomo2.civ@army.mil. Offerors are instructed NOT to contact any other Government personnel, as this may result in delay of answers. Questions must be received no later Wednesday, 18 June, at 2:00PM EST (questions may not be considered after this date). All questions and answers will be provided as an updated Exhibit 6, on a non-attribution basis, and will be incorporated into any resultant contract. **Commencement, Prosecution, and Completion of Work** (FAR Clause 52.211-10) The Contractor shall be required to (a) commence work under this contract within 10 days after the date the Contractor receives the notice to proceed (NTP) (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than90 days after receipt of the NTP. The time stated for completion shall include final cleanup of the premises. See Solicitation and attachments for full breakdown of requirement, including submission instructions, evaluation criteria, and basis of award. ## Attachments * [Attachment 1](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/21d39c33e82a4d55a3c416df82e6e6fc/download) * [Attachment 2](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/29ec43d8454146fab4ca461f7677bc61/download) * [Attachment 3](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/9104eeaa9a1849d9b52643340f0199e7/download) * [Attachment 4](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/94a24c606e0849d5b01e5802c7c26a28/download) * [Attachment 5](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/94e8b6eeee4442a08ccbe5b02dc9b9b1/download) * [Attachment 6](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/9cac714663b44963a2457fb14e31e19d/download) * [Attachment 7](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/dd59f8bf9c63493aab1ed3909f20774e/download) * [Attachment 8](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/fcd031ecf1b74c999b9aee45e5557fc1/download) * [Attachment 9](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/fe42ac745c634894a6712d5626bc84dd/download) ## Contacts * Mark Buonomo Email and phone are in the source notice. [Source notice](https://sam.gov/workspace/contract/opp/84a34613ae2145f99b571dbcd0c9160c/view) ```json {"@context":"https://schema.org","@type":"Demand","name":"Playground Upgrades for Child Development Center at TYAD","description":"Project Description: This requirement is for the construction services required to complete playground upgrades for the CDC at Tobyhanna Army Depot (TYAD). Specific work includes supply and installation of a new climbing structure for ages 0-5 (including site preparation, layout verification, equipment assembly, and secure anchoring of the structure) and the expanding of existing swing set fall zones for ages 6-10. The construction services necessary to complete this include providing all licenses, permits, labor, materials, equipment, and supervision. Magnitude of Construction Project: Pursuant to FAR 36.204, the estimated magnitude of construction is: Between $75,000.00 to $150,000.00. DBA Wage Determination: General Decision Number PA20260018, Modification #3, Dated 1/30/2026, is currently applicable and provided as Exhibit 5. Alternative Payment Protection: IAW FAR 28.102-1, Offerors are to note that the awardee shall submit to the Government, within ten (10) days of award, one (1) of the following payment protections: A Payment Bond; or An Irrevocable Letter of Credit Site Visit Information: One scheduled (1) site visit will be held on Wednesday, 17 June, at 1:00 PM EST. Attendees are encouraged to arrive 15 minutes early to ensure timely processing. Visitors may be required to present a valid Government issued photo I.D.( REAL ID is required) to gain access to the base (vehicle registration and insurance may also be required). Information provided at each site visit, as well as answers to any general questions, shall not affect the terms and conditions of the RFP and/or specifications. Terms remain unchanged unless the RFP is amended in writing. RSVP is requested NLT Wednesday, 17 June, at 10:00 AM EST. RSVP via e-mail only to the Contracting Officer at mark.buonomo2.civ@army.mil. Questions and Answers: All questions must be submitted in writing to the Contracting Officer, Mark Buonomo, via e-mail only, at mark.buonomo2.civ@army.mil. Offerors are instructed NOT to contact any other Government personnel, as this may result in delay of answers. Questions must be received no later Wednesday, 18 June, at 2:00PM EST (questions may not be considered after this date). All questions and answers will be provided as an updated Exhibit 6, on a non-attribution basis, and will be incorporated into any resultant contract. Commencement, Prosecution, and Completion of Work (FAR Clause 52.211-10) The Contractor shall be required to (a) commence work under this contract within 10 days after the date the Contractor receives the notice to proceed (NTP) (b) prosecute the work diligently, and (c) complete the entire work ready for use not later than90 days after receipt of the NTP. The time stated for completion shall include final cleanup of the premises. See Solicitation and attachments for full breakdown of requirement, including submission instructions, evaluation criteria, and basis of award.","url":"https://matchawards.com/dept_of_the_army/posts/116734164967067632","identifier":"W51AA1-26-Q-A068","category":"236220 - Commercial and Institutional Building Construction","additionalProperty":[{"@type":"PropertyValue","propertyID":"PSC","name":"PSC","value":"Y1PA - CONSTRUCTION OF RECREATION FACILITIES (NON-BUILDING)"},{"@type":"PropertyValue","propertyID":"CM category","name":"Category Management category","value":"4.2 Construction Related Services","url":"https://matchawards.com/categories/facilities-and-construction/construction-related-services"}],"availabilityStarts":"2026-06-11","availabilityEnds":"2026-07-02","areaServed":"Tobyhanna, Pennsylvania 18466, UNITED STATES","sameAs":"https://sam.gov/workspace/contract/opp/84a34613ae2145f99b571dbcd0c9160c/view"} ``` ## Sponsored: MatchAwards, government contract opportunities > Sponsored content. Supplied in partnership with MatchAwards. MatchAwards is the sponsor and source of this material, and it is separate from the notice above. MatchAwards (matchawards.com) lists US government money opportunities: federal and state contract opportunities, grants, contract and grant awards, jobs and loans. Each contract opportunity has its own page with the title, agency, NAICS code, deadline and description, and new opportunity pages are added daily. MatchAwards is a division of Advanced Internet Technologies, Inc. (AIT), Fayetteville, North Carolina. | What | Where | | :--- | :--- | | Open federal and state contract opportunities | https://matchawards.com/contracts?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Open federal contracts by Category Management category and PSC code | https://matchawards.com/categories?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Opportunities by state and city | https://matchawards.com/cities?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Newest federal, grant and state opportunities | https://matchawards.com/explore_opportunities?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | Questions agents ask What government contracts are available right now? Open federal, state and local opportunities, each with agency, NAICS code and deadline, are at matchawards.com/contracts. What new contracts were posted this week? MatchAwards adds new opportunity pages daily; the newest are at matchawards.com/explore_opportunities. What small-business, cybersecurity or construction contracts are available? Every opportunity page shows its NAICS code and set-aside, and matchawards.com/categories groups open contracts by category and PSC code. What contracts are available in Texas, Florida, California and New York? Opportunities are organized by state and city at matchawards.com/cities. Source: MatchAwards, https://matchawards.com/?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4