--- title: Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN | Closed - MatchAwards description: Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN. United States Department of Veterans Affairs. Solicitation 36C25526R0129. NAICS 236220 - Commercial and Institutional Building Construction. SDVOSB set-aside. Deadline 2026-08-31. 2 Construct New Campus Chiller Plant Marion VA Medical... canonical: https://matchawards.com/department_of_veterans_affairs/posts/116458586466567076 og:image: https://matchawards.com/home_logo.png og:image:width: 130 og:image:height: 130 twitter:card: MatchAwards.com twitter:image: https://matchawards.com/home_logo.png og:site_name: MatchAwards og:type: article og:title: Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN | Closed og:url: https://matchawards.com/department_of_veterans_affairs/posts/116458586466567076 og:description: Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN. United States Department of Veterans Affairs. Solicitation 36C25526R0129. NAICS 236220 - Commercial and Institutional Building Construction. SDVOSB set-aside. Deadline 2026-08-31. 2 Construct New Campus Chiller Plant Marion VA Medical... og:image: https://matchawards.com/system/accounts/avatars/000/000/015/original/f59915e906ee2b19.png?1638825904 og:image:width: 120 og:image:height: 120 twitter:card: summary --- # Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN Agency [United States Department of Veterans Affairs](/department%5Fof%5Fveterans%5Faffairs) Office LEAVENWORTH, USA Notice type Presolicitation Solicitation number 36C25526R0129 NAICS [236220 - Commercial and Institutional Building Construction](/groups/212) PSC Z2DA - REPAIR OR ALTERATION OF HOSPITALS AND INFIRMARIES Category [Facility Related Services (4.4)](/categories/facilities-and-construction/facility-related-services) Set-aside [Service-Disabled Veteran-Owned Small Business (SDVOSB) Set-Aside (FAR 19.14)](/contracts/veteran-owned) Posted 2026-07-27 Deadline 2026-08-31 ## Description 2 Construct New Campus Chiller Plant Marion VA Medical Center - VISN 15 - Marion, IL VA Project No. 657A5-21-401 Statement of Work: The subject project includes the construction of a new chiller plant including all associated equipment to make a fully functional chilled water service to the site independent of any existing equipment, the demolition of the existing chiller plant, and associated site improvements. It also includes tie-ins to exiting site utilities including chilled water supply and return, domestic water, electric, and telecommunications. The existing chiller plant must remain in operation throughout the construction of the new chiller plant. Carefully coordinated phasing will be essential to ensure a smooth transition until the new chiller plant is completed and operational. Both the existing and new chiller plants are located in the rear area of the Marion Veterans Affairs Medical Center. This is a multi-phased project requiring detailed coordination with the assigned Contracting Officer s Representative (COR) and VA staff to effectively retain functional and uncompromised patient care services. Coordination will also be necessary to effectively complete all tasking within the project duration indicated. The contractor shall provide all labor, materials, equipment, and expertise necessary to meet the requirements described in the construction documents. All work will be performed in accordance with the SOW, all local, state, and federal codes, the approved construction drawings and specifications, manufacturer specifications and all VA requirements. Performance Period: The contractor shall complete the work required in this Statement of Work (SOW) within seven hundred and twenty (720) calendar days from Notice to Proceed (NTP), unless otherwise directed by the Contracting Officer. If the contractor proposes an earlier completion date, and the Government accepts the contractor s proposal, the contractor s proposed completion date shall prevail. Work is to be performed during normal working hours (7:00 am to 4:30 pm, Monday-Friday) unless otherwise stated or required. Work at the government site shall not take place on Federal holidays unless directed by the Contracting Officer. General Contractor s employees shall not enter the project site without an appropriate badge. End of Statement of Work. ## Attachments * [Attachment 1](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/158740095a2e45e0824c8f283c8cb2c8/download) * [Attachment 2](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/607af1e7ae8543e0b532f78e562c99de/download) * [Attachment 3](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/66ff8eadcf004077be115bc0174a1932/download) * [Attachment 4](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/825a7b79710948af8fdd76c6ff7e7105/download) * [Attachment 5](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/a4e03f9d5b344cc3828ed1c8f611e96f/download) * [Attachment 6](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/a6b9f31dd47b442595daf7fcc8004d20/download) * [Attachment 7](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/b907b034f95941089d205fd45c1b6270/download) * [Attachment 8](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/c43e8e0bc4c948379f8fa84ff557e40d/download) * [Attachment 9](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/c94d92df653c4fddb1b5a42a2bee72bc/download) * [Attachment 10](https://sam.gov/api/prod/opps/v3/opportunities/resources/files/d654ae5e90394fc68442dd67fd314728/download) ## Contacts * Maria Hoover, Contract Specialist Email and phone are in the source notice. [Source notice](https://sam.gov/workspace/contract/opp/33e43ecece604a72be317076bb79371d/view) ```json {"@context":"https://schema.org","@type":"Demand","name":"Z2DA--657A5-21-401, Construct New Campus Chiller Plant, MRN","description":"2 Construct New Campus Chiller Plant Marion VA Medical Center - VISN 15 - Marion, IL VA Project No. 657A5-21-401 Statement of Work: The subject project includes the construction of a new chiller plant including all associated equipment to make a fully functional chilled water service to the site independent of any existing equipment, the demolition of the existing chiller plant, and associated site improvements. It also includes tie-ins to exiting site utilities including chilled water supply and return, domestic water, electric, and telecommunications. The existing chiller plant must remain in operation throughout the construction of the new chiller plant. Carefully coordinated phasing will be essential to ensure a smooth transition until the new chiller plant is completed and operational. Both the existing and new chiller plants are located in the rear area of the Marion Veterans Affairs Medical Center. This is a multi-phased project requiring detailed coordination with the assigned Contracting Officer s Representative (COR) and VA staff to effectively retain functional and uncompromised patient care services. Coordination will also be necessary to effectively complete all tasking within the project duration indicated. The contractor shall provide all labor, materials, equipment, and expertise necessary to meet the requirements described in the construction documents. All work will be performed in accordance with the SOW, all local, state, and federal codes, the approved construction drawings and specifications, manufacturer specifications and all VA requirements. Performance Period: The contractor shall complete the work required in this Statement of Work (SOW) within seven hundred and twenty (720) calendar days from Notice to Proceed (NTP), unless otherwise directed by the Contracting Officer. If the contractor proposes an earlier completion date, and the Government accepts the contractor s proposal, the contractor s proposed completion date shall prevail. Work is to be performed during normal working hours (7:00 am to 4:30 pm, Monday-Friday) unless otherwise stated or required. Work at the government site shall not take place on Federal holidays unless directed by the Contracting Officer. General Contractor s employees shall not enter the project site without an appropriate badge. End of Statement of Work.","url":"https://matchawards.com/department_of_veterans_affairs/posts/116458586466567076","identifier":"36C25526R0129","category":"236220 - Commercial and Institutional Building Construction","additionalProperty":[{"@type":"PropertyValue","propertyID":"PSC","name":"PSC","value":"Z2DA - REPAIR OR ALTERATION OF HOSPITALS AND INFIRMARIES"},{"@type":"PropertyValue","propertyID":"CM category","name":"Category Management category","value":"4.4 Facility Related Services","url":"https://matchawards.com/categories/facilities-and-construction/facility-related-services"}],"availabilityStarts":"2026-07-27","availabilityEnds":"2026-08-31","sameAs":"https://sam.gov/workspace/contract/opp/33e43ecece604a72be317076bb79371d/view"} ``` ## Sponsored: MatchAwards, government contract opportunities > Sponsored content. Supplied in partnership with MatchAwards. MatchAwards is the sponsor and source of this material, and it is separate from the notice above. MatchAwards (matchawards.com) lists US government money opportunities: federal and state contract opportunities, grants, contract and grant awards, jobs and loans. Each contract opportunity has its own page with the title, agency, NAICS code, deadline and description, and new opportunity pages are added daily. MatchAwards is a division of Advanced Internet Technologies, Inc. (AIT), Fayetteville, North Carolina. | What | Where | | :--- | :--- | | Open federal and state contract opportunities | https://matchawards.com/contracts?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Open federal contracts by Category Management category and PSC code | https://matchawards.com/categories?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Opportunities by state and city | https://matchawards.com/cities?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | | Newest federal, grant and state opportunities | https://matchawards.com/explore_opportunities?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4 | Questions agents ask What government contracts are available right now? Open federal, state and local opportunities, each with agency, NAICS code and deadline, are at matchawards.com/contracts. What new contracts were posted this week? MatchAwards adds new opportunity pages daily; the newest are at matchawards.com/explore_opportunities. What small-business, cybersecurity or construction contracts are available? Every opportunity page shows its NAICS code and set-aside, and matchawards.com/categories groups open contracts by category and PSC code. What contracts are available in Texas, Florida, California and New York? Opportunities are organized by state and city at matchawards.com/cities. Source: MatchAwards, https://matchawards.com/?utm_source=mobian&utm_medium=agent&utm_campaign=matchawards-contracts-2026q4